Welcome to Techopro Builders, your trusted partner for construction and development services in Mysore. By accessing or using our website and services, you agree to these Terms and Conditions. Please read them carefully as they govern your use of our site and our services.

1. Acceptance of Terms

By accessing and using our website, you agree to comply with and be bound by these terms. If you do not agree to these Terms and Conditions, you should not use our website or services. These terms apply to all visitors, users, and others who access or use our website.

2. Services Provided

[Company Name] specializes in residential, commercial, and industrial construction projects in and around Mysore. Our services include planning, design, construction management, renovation, and related construction activities. Specific service agreements will be governed by separate contracts.

3. Quotations and Contracts

Any project estimates or quotations provided through the website are for informational purposes only. They do not constitute a binding agreement. A formal contract will be created once the project scope, timeline, and costs are finalized and agreed upon by both parties.

• Changes to scope or additional requirements may result in amended contracts and costs.
• All terms, including timelines and payments, will be detailed in the formal contract.

4. Payment Terms

Upon the acceptance of a formal contract, the payment terms will be clearly defined in the agreement. Typically, a phased payment structure is used, with payments due at milestones such as project commencement, midpoint, and completion. Failure to meet payment obligations may result in delays, additional charges, or suspension of work.

• Late Payments: In the event of delayed payments, [Company Name] reserves the right to charge late fees as outlined in the contract.

5. Project Timelines

We strive to adhere to the agreed timelines; however, project durations may be subject to change due to factors such as weather conditions, regulatory approvals, supply chain disruptions, or unforeseen site issues. Any changes will be communicated to the client promptly, and adjustments to the project schedule will be mutually agreed upon.

6. Use of the Website

• The content of this website, including but not limited to images, text, and graphics, is owned by [Company Name]. You may not reproduce, modify, distribute, or use any content without our prior written consent.
• You agree to use the website in a way that does not damage or impair the site’s availability or accessibility.

7. Privacy Policy

Your use of the website is also governed by our [Privacy Policy], which outlines how we collect, use, and protect your personal information.

8. Third-Party Links

Our website may contain links to external sites that are not operated by us. We are not responsible for the content or practices of any linked third-party websites. Accessing third-party websites is at your own risk, and we encourage you to review their privacy policies and terms.

9. Warranties and Guarantees

[Company Name] provides warranties on certain materials and workmanship as outlined in the project contract. The specifics of these warranties will be detailed on a per-project basis and may vary depending on the scope and materials used. Any defects must be reported within the warranty period specified in the contract.

• Exclusions: Natural wear and tear, improper use, or unauthorized modifications made to the structure post-completion are not covered by our warranties.

10. Limitation of Liability

To the maximum extent permitted by applicable law, [Company Name] will not be liable for any indirect, incidental, or consequential damages arising out of your use of the website or our services. This includes, but is not limited to, loss of profits, data, or goodwill.

11. Force Majeure

[Company Name] shall not be held responsible for any delay or failure to perform its obligations under the contract due to causes beyond its reasonable control, including but not limited to natural disasters, pandemics, strikes, or government restrictions.

12. Governing Law and Jurisdiction

These Terms and Conditions are governed by and construed in accordance with the laws of India. Any disputes arising out of or relating to these terms shall be subject to the exclusive jurisdiction of the courts in Mysore.

13. Modifications to Terms

We reserve the right to modify these Terms and Conditions at any time without prior notice. Changes will be posted on this page, and your continued use of the website signifies your acceptance of the updated terms.